INVITATION TO BID
WPCF IMPROVEMENTS – PHASE 2
TOWN OF WAREHAM, MA
CONTRACT NO. 2024-WW-01
SRF NO. CWSRF-12430
In accordance with M.G.L. c. 149, 44D ½ and 44D ¾, and 810 CMR 9.00 and 10.00, the Town of Wareham has established a two-phase process for the selection of General Contractors and filed sub-bid Subcontractors for the construction of the Wareham Water Pollution Control Facility for the Town of Wareham, MA. Only those contractors/subcontractors prequalified to bid on the above referenced project shall be invited to submit bids and/or sub-bids as part of Phase 2 of the selection process. Sealed bids will be received at the Water Pollution Control Facility (WPCF), 6 Tony’s Lane, Wareham, Massachusetts, 02571, Attn: Director of Water Pollution Control until 2:00 p.m. local time on June 26, 2024, and at that place and time will be publicly opened and read aloud. All bids will be valid only when accompanied by a current certificate of eligibility and an update statement (Form CQ3) issued by the Division of Capital Asset Management and Maintenance (DCAMM), showing that the General Bidder has the classification of Sewage and Water Treatment Plants and that the Filed Sub Bidders have the classification matching the Filed Sub-Bid being submitted. Filed subcontractor sealed bids designated herein for construction of the above referenced project will be received at the Water Pollution Control Facility (WPCF), 6 Tony’s Lane, Wareham, Massachusetts, Attn: Director of Water Pollution Control until 2:00 p.m. local time on June 12, 2024, and at that place and time will be publicly opened and read aloud. All bids will be valid only when accompanied by a current certificate of eligibility and updated statement issued by the Division of Capital Asset Management and Maintenance (DCAMM), showing that the Filed Sub Bidders have the classification matching the Filed Sub-Bid being submitted.
The Project is being bid under the provisions of M.G.L. c.149, s44D. Bidding and award of this Contract shall be required to comply with Massachusetts General Law Chapter 149, Section 44A-44J, and all other applicable Massachusetts General Laws.
Separate sealed Bids will be received for the following: General Construction – Sewage and Water Treatment Plants; Masonry; Miscellaneous and Ornamental Iron; Waterproofing, Dampproofing, and Caulking; Roofing and Flashing; Metal Windows; Painting; Fire Protection; Heating, Ventilating, and Air Conditioning; Plumbing; Electrical and Instrumentation.
The Work consists of the construction of upgrades to existing water pollution control facility in accordance with the Bidding Documents heretofore prepared by GHD Inc. 730 calendar days will be allowed for contractor to achieve substantial completion and 790 calendar days to achieve final completion.
GHD Inc. is the Issuing Office for this Project. The Contract Documents may be examined at the following locations: GHD Inc. (by appointment), 1545 Iyannough Road, Hyannis, MA 02601; www.constructconnect.com; www.construction.com; www.projectdog.com.
Copies of Bidding Documents may be purchased at the office of GHD, 1545 Iyannough Road, Hyannis, MA 02601 after 12:00 p.m. on May 15, 2024 (by appointment only). Bidding documents are available in both electronic and hardcopy form. Direct all questions regarding distribution of Bidding Document to Laura Muir, 774-470-1633, laura.muir@ghd.com.
All other questions shall be submitted in writing to Mike Krieger at mike.krieger@ghd.com. The subject heading for all e-mails shall be: Subject: Wareham WPCF Improvements Phase 2.
Disadvantaged Business Enterprise (DBE) goals are applicable to the total dollars paid to the construction contract. The goals for this project are a minimum of 4.20 percent D/MBE participation and 4.50 percent D/WBE participation by certified DBEs. The two low bidders shall submit completed DBE forms (EEO-DEP-190C & EEO-DEP-191C and the DBE Certification of United States Citizenship form) by the close of business on the third business day after Bid opening. Failure to comply with the requirements of this paragraph may be deemed to render a proposal non-responsive. No waiver of any provision of this section will be granted unless approved by the Department of Environmental Protection (MassDEP).
Minimum Wage Rates as determined by the Commissioner of Department of Workforce Development under the provision of the Massachusetts General Laws, Chapter 149, Sections 26 to 27D, as amended, apply to this project. It is the responsibility of the contractor, before bid opening, to request if necessary, any additional information on Minimum Wage Rates for those trades people who may be employed for the proposed work under this contract. Federal Minimum Wage Rates as determined by the United States Department of Labor under the Davis-Bacon Act also apply to this project.
The Town of Wareham reserves the right to waive any informalities or to reject any or all Bids.
Bidders are required to certify, under penalty of perjury, that Bids have been prepared without collusion with other Bidders, subcontractors, suppliers, etc. This certification is included with the Bid Form and each Bidder must sign in the space provided.
The Project is to be funded in part by the Massachusetts Water Pollution Abatement Trust (the “Trust”).
The Project requires compliance with the Department of Environmental Protection’s Diesel Retrofit Program.
This project is funded by appropriations that contain “Build America, Buy America Act” (BABA) requirements. Note that the BABA requirements are waived for this Project based on EPA’s Decision Memorandum titled Adjustment Period Waiver of Section 70914(a) of P.L. 117-58, Build America, Buy America Act for SRF Projects that have Initiated Design Planning prior to September 2, 2022.
The Project is subject to the American Iron and Steel requirements of P.L. 113-76, the Consolidated Appropriations Act of 2014.
A non-mandatory Pre-Bid Conference will be held at 10:00 a.m. on May 22, 2024, at the Water Pollution Control Facility (WPCF), 6 Tony’s Lane, Wareham, Massachusetts. Representatives of Owner and Engineer will be present to discuss the Project. Bidders are encouraged to attend and participate in the conference.
ZONING BOARD OF APPEALS
54 Marion Road
Wareham, MA 02571
NOTICE OF PUBLIC HEARING
The Zoning Board of Appeals will hold a public hearing on June 12, 2024, at 6:30 p.m. in Room 320 of the Wareham Multi-Service Center, 48 Marion Road, Wareham, MA 02571 to consider Petition # 21-24 for a Special Permit and/or Variance from the requirements of Article 6, Table 628 and Article 13, Section 1352 and Section 1353 under the Wareham Zoning By-Laws, to Heidi & Allan Bain, c/o William Lockwood of Lockwood Architects of Onset, MA proposing 1st and 2nd floor additions and renovations at the property located at, 16 Pleasant Ave., Wareham, MA (Assessors Map 1, Lot 68) in the OV-2 zoning district.
Nazih Elkallassi, Chairman
First Notice: May 23, 2024
Second Notice: May 30, 2024
CITATION ON PETITION
TO CHANGE NAME
Commonwealth of Massachusetts
The Trial Court, Probate and Family Court
Plymouth Probate and Family Court
52 Obery Street, Suite 1130
Plymouth, MA 02360, (508) 747-6204
Docket No. PL242C0117CA
In the matter of: Cynthia Anne Servais
A Petition to Change Name of Adult has been filed by Cynthia Anne Servais of Wareham, MA requesting that the Court enter a Decree changing their name to:Cynthia Anne Noblet.
IMPORTANT NOTICE
Any person may appear for purposes of objecting to the petition by filing an appearance at: Plymouth Probate and Family Court before 10:00 a.m. on the return day of 06/05/2024.
This is NOT a hearing date, but a deadline by which you must file a written appearance if you object to this proceeding.
Witness: Hon. Patrick W. Stanton,
First Justice of this Court
Date: May 06, 2024
Matthew J. McDonough, Register of Probate
COMMONWEALTH OF MASSACHUSETTS
LAND COURT
DEPARTMENT OF THE TRIAL COURT
Docket No. 24 SM 001410
ORDER OF NOTICE
TO: Salvador Matos, Paula Cabral-Matos
and to all persons entitled to the benefit of the Servicemembers Civil Relief Act, 50 U.S.C. c. 50 §3901 (et seq):
Nationstar Mortgage LLC
claiming to have an interest in a Mortgage covering real property in 239 Sandwich Road, Wareham, MA 02571, given by Salvador Matos and Paula Cabral-Matos to Nationstar Mortgage LLC dated December 27, 2004 and recorded in the Plymouth County Registry of Deeds in Book 29852, Page 22, has/have filed with this court a complaint for determination of Defendant’s/Defendants’ Servicemembers status.
If you now are, or recently have been, in the active military service of the United States of America, then you may be entitled to the benefits of the Servicemembers Civil Relief Act. If you object to a foreclosure of the above -mentioned property on that basis, then you or your attorney must file a written appearance and answer in this court at Three Pemberton Square, Boston, MA 02108 on or before 6/24/2024 or you may lose the opportunity to challenge the foreclosure on the ground of noncompliance with the Act.
Witness, GORDON H. PIPER
Chief Justice of this Court on 5/9/2024
Attest: Deborah J. Patterson, Recorder
CITATION ON PETITION
FOR ORDER OF
COMPLETE SETTLEMENT
Commonwealth of Massachusetts
The Trial Court
Plymouth Probate and Family Court
52 Obery St. Suite 1130
Plymouth, MA 02360
(508) 747-6204
Docket No. PL21P1663EA
Estate Of: Leon Perry Pettiford
A Petition for Order of Complete Settlement has been filed by Patricia A Pettiford of Boston MA requesting that the court enter a formal Decree of Complete Settlement including the allowance of a final account, First and Final and other such relief as may be requested in the Petition.
IMPORTANT NOTICE
You have the right to obtain a copy of the Petition from the Petitioner or at the court. You have a right to object to this proceeding. To do so, you or your attorney must file a written appearance and objection at this court before: 10:00 a.m. on the return day of 06/14/2024.
This is NOT a hearing date, but a deadline by which you must file a written appearance and objection if you object to this proceeding. If you fail to file a timely written appearance and objection followed by an affidavit of objections within thirty (30) days of the return day, action may be taken without further notice to you.
Witness: Hon. Patrick W. Stanton,
First Justice of this Court.
Date: May 14, 2024
Matthew J. McDonough, Register of Probate
ZONING BOARD OF APPEALS
54 Marion Road
Wareham, MA 02571
NOTICE OF PUBLIC HEARING
The Zoning Board of Appeals will hold a public hearing on June 12, 2024, at 6:30 p.m. in Room 520 of the Wareham Multi-Service Center, 48 Marion Road, Wareham, MA 02571 to consider Petition # 25-24 for a Special Permit or Variance from the requirements of Article 6, Table 628 and Article 13, Section 1352 and Section 1353 under the Wareham Zoning By-Laws, to Kimberly Lonis-Scheub, c/o Trinity Solar, Inc. of 20 Patterson Brook Road, Wareham, MA proposing to install an external battery enclosure on the exterior of the property located at, 150 Pinehurst Drive, Wareham, MA (Assessors Map 46A1, Lot 70) in the R-30 zoning district.
Nazih Elkallassi, Chairman
First Notice: May 23, 2024
Second Notice: May 30, 2024
ZONING BOARD OF APPEALS
54 Marion Road
Wareham, MA 02571
NOTICE OF PUBLIC HEARING
The Zoning Board of Appeals will hold a public hearing on June 12, 2024, at 6:30 p.m. in Room 320 of the Wareham Multi-Service Center, 48 Marion Road, Wareham, MA 02571 to consider Petition # 20-24 for a Special Permit and/or a Variance from the requirements of Article 6, Table 628 and Article 13 under the Wareham Zoning By-Laws, to Jennifer Dziuba & Michael Foley, c/o William Lockwood of Lockwood Architects of Onset, MA proposing interior renovations and second floor additions at the property located at, 33 West Central Ave., Wareham, MA (Assessors Map 1, Lot 677) in the OV-2 zoning district.
Nazih Elkallassi, Chairman
First Notice: May 23, 2024
Second Notice: May 30, 2024
ZONING BOARD OF APPEALS
54 Marion Road
Wareham, MA 02571
NOTICE OF PUBLIC HEARING
The Zoning Board of Appeals will hold a public hearing on June 12, 2024, at 6:30 p.m. in Room 320 of the Wareham Multi-Service Center, 48 Marion Road, Wareham, MA 02571 to consider Petition # 23-24 for a Special Permit or a Variance from the requirements of Article 6, Table 628 and Article 13, Section 1352 and Section 1353 under the Wareham Zoning By-Laws, to Margaret Dwyer & Michael Hogan, c/o William Lockwood of Lockwood Architects of Onset, MA proposing renovations and dorner additions at the property located at, 5 Maple Street, Wareham, MA (Assessors Map 3, Lot 1016) in the MR-30 zoning district.
Nazih Elkallassi, Chairman
First Notice: May 23, 2024
Second Notice: May 30, 2024
ZONING BOARD OF APPEALS
54 Marion Road
Wareham, MA 02571
NOTICE OF PUBLIC HEARING
The Zoning Board of Appeals will hold a public hearing on June 12, 2024, at 6:30 p.m. in Room 520 of the Wareham Multi-Service Center, 48 Marion Road, Wareham, MA 02571 to consider Petition #24-24 for a Variance(s) to Varoujan Garabedian of 57 West Central Avenue, Wareham, MA proposing to install a 6’7” x 8’7” sauna with electric heater and seeking relief from Building Commissioner’s denial based on two structures that were erected in 2019 at the property located at, 57 West Central Avenue, Wareham, MA (Assessors Map 1, Lot 753) in the OV-2 district.
Nazih Elkallassi, Chairman
First Notice: May 23, 2024
Second Notice: May 30, 2024
CITATION ON PETITION
FOR FORMAL ADJUDICATION
Commonwealth of Massachusetts
The Trial Court
Plymouth Probate and Family Court
52 Obery St. Suite 1130
Plymouth, MA 02360
(508) 747-6204
Docket No. PL24P0971EA
Estate of: Daniel Joseph McAssey
Also known as: Daniel J McAssey
Date of Death: 05/07/2023
To all interested persons:
A Petition for Formal Adjudication of Intestacy and Appointment of Personal Representative has been filed by Mary K McAssey of Plymouth MA requesting that the Court enter a formal Decree and Order and for such other relief as requested in the Petition.
The Petitioner requests that Mary K McAssey of Plymouth MA be appointed as Personal Representative(s) of said estate to serve Without Surety on the bond in unsupervised administration.
IMPORTANT NOTICE
You have the right to obtain a copy of the Petition from the Petitioner or at the Court. You have a right to object to this proceeding. To do so, you, or your attorney must file a written appearance and objection at this Court before: 10:00 a.m. on the return day of 06/10/2024.
This is NOT a hearing date, but a deadline by which you must file a written appearance and objection if you object to this proceeding. If you fail to file a timely written appearance and objection followed by an affidavit of objections within thirty (30) days of the return day, action may be taken without further notice to you.
UNSUPERVISED ADMINISTRATION UNDER THE MASSACHUSETTS UNIFORM PROBATE CODE (MUPC)
A Personal Representative appointed under the MUPC in an unsupervised administration is not required to file an inventory or annual accounts with the Court. Persons interested in the estate are entitled to notice regarding the administration directly from the Personal Representative and may petition the Court in any matter relating to the estate, including the distribution of assets and expenses of administration.
Witness: Hon. Patrick W. Stanton,
First Justice of this Court
Date: May 10, 2024
Matthew J. McDonough, Register of Probate
ZONING BOARD OF APPEALS
54 Marion Road
Wareham, MA 02571
NOTICE OF PUBLIC HEARING
The Zoning Board of Appeals will hold a public hearing on June 12, 2024, at 6:30 p.m. in Room 320 of the Wareham Multi-Service Center, 48 Marion Road, Wareham, MA 02571 to consider Petition #26-24 for an Appeal of Building Inspector Notice of Violation per the requirements of the Massachusetts State Building Code, to Richard E. & Audrey Kradin c/o Dennis J. Conry Esq. of 245 Main Street, Wareham, MA for the property located at, 24 Cove Street, Wareham, MA (Assessors Map 2, Lot 264) in the OV-R zoning district.
Nazih Elkallassi, Chairman
First Notice: May 23, 2024
Second Notice: May 30, 2024
NOTICE OF MORTGAGEE’S
SALE OF REAL ESTATE
615 Main Street, Wareham, MA 02571
By virtue and in execution of the Power of Sale contained in a certain mortgage given by 1111 Tipping Point LLC to Signature Lending, LLC, dated June 16, 2023, and recorded in the Plymouth County Registry of Deeds in Book 58013, Page 22, of which mortgage the undersigned is the present holder, for breach of the conditions of said mortgage and for the purpose of foreclosing the same will be sold at Public Auction at 11:00 A.M. on June 13, 2024 on the mortgaged premises located at 615 Main Street, Wareham, Plymouth County, Massachusetts, all and singular the premises described in said mortgage,
To wit:
All of the interest in the real estate located at 615 Main Street, Wareham, Plymouth County, Massachusetts and said land together with the buildings and improvements thereon is bounded and described as follows:
The land in that part of Wareham, Plymouth County, Massachusetts, together with the buildings thereon, near Smith’s Corner (so-called) on the Northerly side of the Main State Highway leading from Wareham to South Wareham and bounded and described as follows:
Beginning at a stake in the line of the State Highway, it being the southwesterly corner of the land now or formerly of Howard W. Bradley;
Thence running North by land of said Bradley, Two hundred and no/100 (200.0) feet to a stake;
Thence turning and running westerly by other land now or formerly of Robert L. Vose, Seventy-five and no/100 (75.0) feet to a stake;
Thence turning and running southerly by other land now or formerly of Robert L. Vose, Two hundred and no/100 (200.0) feet to a stake in the line of the Main State Highway;
Thence Easterly in line of the Main State Highway, Seventy-five and no/100 (75.0) feet to the first mentioned bound and point of beginning.
Containing fifteen thousand square feet.
Together with all rights, privileges and easements connected therewith and subject to restrictions and easements of record insofar as same are in force and applicable.
For Grantor’s Title, see Deed recorded in the Plymouth County Registry of Deeds in Book 58013, Page 19.
Premises to be sold and conveyed subject to and with the benefit of all rights, rights of way, restrictions, easements, covenants, liens or claims in the nature of liens, improvements, public assessments, any and all unpaid taxes, tax titles, tax liens, water and sewer liens and any other municipal assessments or liens or existing encumbrances of record which are in force and are applicable, having priority over said mortgage, whether or not reference to such restrictions, easements, improvements, liens or encumbrances is made in the deed.
Terms of sale: A deposit of Ten Thousand Dollars ($10,000.00) by certified or bank check will be required to be paid by the purchaser at the time and place of sale. The balance is to be paid by wire transfer or certified check at the Law Offices of Robert Pellegrini, Inc., d/b/a PK Boston Law, 63 Main Street, Suite 1, Bridgewater, MA 02324 within thirty (30) days from the date of sale. Deed will be provided to purchaser for recording upon receipt in full of the purchase price. In the event of an error in this publication, the description of the premises contained in said mortgage shall control.
Other terms, if any, to be announced at the sale.
Signature Lending, LLC
Present holder of said mortgage
By its Attorneys,
PK Boston Law
63 Main Street, Suite 1
Bridgewater, MA 02324
(508) 807-1131
Wareham Week
May 23, 2024, May 30, 2024 and June 6, 2024
CITATION ON PETITION
FOR FORMAL ADJUDICATION
Commonwealth of Massachusetts
The Trial Court
Plymouth Probate and Family Court
52 Obery St. Suite 1130
Plymouth, MA 02360
(508) 747-6204
Docket No. PL24P1064EA
Estate of: Bernard John Hennessy
Also known as: Bernard J Hennessy
Date of Death: 10/28/2023
To all interested persons:
A Petition for Formal Probate of Will with Appointment of Personal Representative has been filed by Cathleen H. Summers of Acton MA requesting that the Court enter a formal Decree and Order and for such other relief as requested in the Petition.
The Petitioner requests that Cathleen H. Summers of Acton MA be appointed as Personal Representative(s) of said estate to serve Without Surety on the bond in unsupervised administration.
IMPORTANT NOTICE
You have the right to obtain a copy of the Petition from the Petitioner or at the Court. You have a right to object to this proceeding. To do so, you, or your attorney must file a written appearance and objection at this Court before: 10:00 a.m. on the return day of 06/13/2024.
This is NOT a hearing date, but a deadline by which you must file a written appearance and objection if you object to this proceeding. If you fail to file a timely written appearance and objection followed by an affidavit of objections within thirty (30) days of the return day, action may be taken without further notice to you.
UNSUPERVISED ADMINISTRATION UNDER THE MASSACHUSETTS UNIFORM PROBATE CODE (MUPC)
A Personal Representative appointed under the MUPC in an unsupervised administration is not required to file an inventory or annual accounts with the Court. Persons interested in the estate are entitled to notice regarding the administration directly from the Personal Representative and may petition the Court in any matter relating to the estate, including the distribution of assets and expenses of administration.
Witness: Hon. Patrick W. Stanton,
First Justice of this Court
Date: May 13, 2024
Matthew J. McDonough, Register of Probate
TOWN OF WAREHAM
Legal Notice to Bidders
INVITATION FOR BID
SEALED BIDS for Janitorial Services for Town of Wareham Owned Buildings commencing July 1, 2024 through June 30, 2025, with renewal options for two additional one-year periods shall be received at the offices of the MUNICIPAL MAINTENANCE, 95 Charge Pond Road, Wareham, MA 02571 until 10:30am June 11, 2024. Bids must be made in a sealed envelope clearly marked “Janitorial Services Bid – June 11, 2024”
The Town of Wareham is an affirmative action, equal opportunity owner/purchaser.
TOWN OF WAREHAM
Legal Notice to Bidders
INVITATION FOR BID
SEALED BIDS for Town of Wareham Purchase and Delivery of Propane (Liquefied Petroleum) Gases commencing July 1, 2024 through June 30, 2025 with renewal options for two additional one-year periods, shall be received at the offices of the MUNICIPAL MAINTENANCE, 95 Charge Pond Road, Wareham, MA 02571 until 10:00am June 11, 2024. Bids must be made in a sealed envelope clearly marked “Supply and Delivery of Propane”
The Town of Wareham is an affirmative action, equal opportunity owner/purchaser.
